Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 1 of 32
San Jose Job Corps Center · Evaluation of Brero's Delay Analysis · Evaluation of Brero's Inefficiency Analysis
Slide 1
Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 2 of 32
San Jose Job Corps Center
Brero Analysis
J F M A M J J A S O
1993
N
D
J
F
M
A
M
J
J
A
S
O
1994
N
Notice to Proceed Contract Term - 490 days
4
Substantial Completion
8
Total Delay 162 days
Actual Construction 652 days
17
Completion
162 days Compensable
LEGEND
Projected As-Built Delay
Slide 2
Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 3 of 32
San Jose Job Corps Center
Brero Analysis Corrections
J F M A M J J A S O
1993
N
D
J
F
M
A
M
J
J
A
S
O
1994
N
Notice to Proceed Contract Term - 490 days
4
Substantial Completion
8
Total Delay 162 days
Actual Construction 652 days
17
Completion
1.
Actual Substantial Completion October 18, 2004
162 days Compensable
LEGEND
Projected As-Built Delay
Slide 3
Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 4 of 32
San Jose Job Corps Center
Brero Analysis Corrections
J F M A M J J A S O
1993
N
D
J
F
M
A
M
J
J
A
S
O
1994
N
Notice to Proceed Contract Term - 490 days
4
Substantial Completion
8
Total Delay 132 days
Actual Construction 622 days
18
Actual Substantial Completion
1.
Actual Substantial Completion October 18, 2004
132 days Compensable
LEGEND
Projected As-Built Delay
Slide 4
Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 5 of 32
San Jose Job Corps Center
Slide 5
Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 6 of 32
San Jose Job Corps Center
Slide 6
Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 7 of 32
San Jose Job Corps Center
Slide 7
Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 8 of 32
San Jose Job Corps Center
Brero Analysis Corrections
J F M A M J J A S O
1993
N
D
J
F
M
A
M
J
J
A
S
O
1994
N
Notice to Proceed Contract Term - 490 days
4
Substantial Completion
8
Total Delay 132 days
Actual Construction 622 days
18
Actual Substantial Completion
1. 2.
Actual Substantial Completion October 18, 2004. Time Extensions to September 9, 2004.
132 days Compensable
LEGEND
Projected As-Built Delay
Slide 8
Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 9 of 32
San Jose Job Corps Center
Brero Analysis Corrections
J F M A M J J A S O
1993
N
D
J
F
M
A
M
J
J
A
S
O
1994
N
Notice to Proceed Contract Term - 490 days + 1+ 90 + 2
4
Substantial Completion
9
Actual Construction 622 days
18
Actual Substantial Completion
1. 2.
Actual Substantial Completion October 18, 2004. Time Extensions to September 9, 2004.
132 days Compensable
LEGEND
Projected As-Built Delay
Slide 9
Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 10 of 32
San Jose Job Corps Center
Brero Analysis Corrections
J F M A M J J A S O
1993
N
D
J
F
M
A
M
J
J
A
S
O
1994
N
Notice to Proceed Contract Term - 490 days + 1+ 90 + 2
4
Substantial Completion
9
Total Delay 39 days
Actual Construction 622 days
18
Actual Substantial Completion
1. 2.
Actual Substantial Completion October 18, 2004. Time Extensions to September 9, 2004.
39 days Compensable
LEGEND
Projected As-Built Delay
Slide 10
Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 11 of 32
San Jose Job Corps Center
Slide 11
Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 12 of 32
San Jose Job Corps Center
Slide 12
Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 13 of 32
San Jose Job Corps Center
Slide 13
Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 14 of 32
San Jose Job Corps Center · Contract Modification # 8 extended time of performance to September 9, 1994 (substantial completion). · Substantial Completion was achieved on October 18, 1994. · Therefore. delay period under consideration is from September 9, 1994 to October 18, 1994, or 39 days.
Slide 14
Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 15 of 32
San Jose Job Corps Center · According to Brero's TIA, delays from September 9 to October 18, 1994 resulted from the following:
- COP 192 Provide 6x8 concrete walk (1 day September 9 to September 10, 1994) - Contractor extended performance of contract work inexcusable (19 days September 10 to September 29, 1994) - COP 209 Additional Soil Amendment (1 day September 29 to October 8, 1994) - COP 234 Screens over wall louvers (10 days October 8 to October 18, 1994)
Slide 15
Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 16 of 32
San Jose Job Corps Center - Mod. 11
Slide 16
Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 17 of 32
San Jose Job Corps Center Mod. 11
Slide 17
Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 18 of 32
San Jose Job Corps Center Mod. 11
Slide 18
Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 19 of 32
San Jose Job Corps Center · According to Brero's TIA, delays from September 9 to October 18, 1994, 39 days are inexcusable. Therefore, Brero is not entitled to any extended performance costs. · According to the Contract, Brero is subject to liquidated damages in the amount of $9,165 (39 x $235).
Slide 19
Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 20 of 32
San Jose Job Corps Center Liquidated Damages
Slide 20
Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 21 of 32
San Jose Job Corps Center Liquidated Damages
Slide 21
Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 22 of 32
San Jose Job Corps Center
Slide 22
Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 23 of 32
San Jose Job Corps Center Brero's LOP Analysis
Slide 23
Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 24 of 32
San Jose Job Corps Center Brero's LOP Analysis
Months with no framing fragnets
Total LOP Hrs w/no Impacts
7411.56
Slide 24
Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 25 of 32
San Jose Job Corps Center Brero's LOP Analysis
Examples of Inefficiencies with no framing fragnets
61%
N had no fragnets
97%
M had no fragnets
Slide 25
Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 26 of 32
San Jose Job Corps Center Brero's LOP Analysis
Examples of Inefficiencies with no framing fragnets
September 1993
85%
February 1994
F had no fragnets
64%
H had no fragnets
Slide 26
Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 27 of 32
San Jose Job Corps Center Empirical Resource Curves used in lieu of actual units installed
Slide 27
Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 28 of 32
San Jose Job Corps Center Certified Payrolls and Job Cost Report
Slide 28
Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 29 of 32
San Jose Job Corps Center Certified Payrolls and Job Cost Report
Slide 29
Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 30 of 32
San Jose Job Corps Center Certified Payrolls and Job Cost Report
Slide 30
Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 31 of 32
San Jose Job Corps Center Inefficiency During Roof Framing
February 1994
73%
76%
Slide 31
Case 1:00-cv-00775-TCW
Document 57-3
Filed 04/28/2006
Page 32 of 32
San Jose Job Corps Center Inefficiency During Roof Framing
March 1994
69%
Slide 32
Free Notice (Other) - District Court of Federal Claims - federal
| File Size: | 1,873.1 kB |
| Pages: | 32 |
| Date: | April 28, 2006 |
| File Format: | |
| State: | federal |
| Category: | District |
| Author: | unknown |
| Word Count: | 1,224 Words, 7,572 Characters |
| Page Size: | Letter (8 1/2" x 11") |
| URL |
https://www.findforms.com/pdf_files/cofc/639/57-3.pdf |
| Download Notice (Other) - District Court of Federal Claims ( 1,873.1 kB) |
Preview Notice (Other) - District Court of Federal Claims
Popular Searches
United States Free Forms
Canada Free Forms
United Kingdom Free Forms
Australia Free Forms